Understand the permitting process and ways to minimize the possibility of permitting delays.
Permitting for construction projects can be, and often is, a complicated undertaking. From knowing when and which permits are required to navigating the necessary bureaucracy to obtain permits, even a simple misstep in the permitting process can lead to delays and added costs. Moreover, the permitting process, which requires the complex coordination of many parties, often with competing interests, provides many opportunities for someone to drop the ball. After a brief review of the general types of permits and the repercussions of delay, this topic will focus on the leading reasons for permitting delays; what an owner, contractor, or design professional can do to minimize the possibility of permitting delay; and what to do to mitigate the impact of permitting delays should they occur. Using real-life examples to illustrate the material presented, you will gain a very practical understanding of the what, why, and how, of permitting delays and delay avoidance and mitigation.
Agenda
Faculty
Fritz T. Marth, P.E., CFCC
GREYHAWK
- Executive consultant with GREYHAWK, a nationally recognized construction management and claims consulting firm
- Areas of practice include schedule delay analysis, cost damages analysis, and litigation support
- Recognized and testified as an expert in courts and in arbitration forums
- Licensed Professional Engineer and a Certified Forensic Claims Consultant
- Presents seminars to contractors, attorneys, and other project stakeholders on topics related to claims avoidance, mitigation, and analysis, with focus on delay and disruption claims
- Member of American Society of Civil Engineers, The Association for the Advancement of Cost Engineering, and the American Bar Association - Forum on Construction Law
- M.S. and B.S. degrees in civil engineering, Drexel University
- Can be contacted at 856-608-7062 or [email protected]
All of your training, right here at Lorman.
Pay once and get a full year of unlimited training in any format, any time!
- Live Webinars
- OnDemand Webinars
- MP3 Downloads
- Course Manuals
- Audio Recordings*
- Executive Reports
- White Papers and Articles
- Sponsored Live Webinars
Additional benefits include:
- State Specific Credit Tracker
- Members Only Newsletter
- All-Access Pass Course Concierge
* For audio recordings you only pay shipping
Questions? Call 877-296-2169 to speak with a real person.
More Program Information
Access to all training products $699/year
Unlimited Lorman Training
With the All-Access Pass there is no guessing what you will need for your yearly training budget. $699 will cover all of your training needs for an entire year!
Easy Registrations
Once you purchase your All-Access Pass you will never be any further than one-click away from attending any Lorman training course.
Invest in Yourself
You haven't gotten to where you are professionally by luck alone; it's taken a lot of hard work and training. Invest in yourself with the All-Access Pass.
